Pence Kelley- Contract - Laserfiche WebLink

Home Browse Search

Shop Drawings, Product Data and Samples, ~-ert~}~-~'ef~e- ~e~ -~ese ~€ -s4iesl~g -€eF -sefl€er~aRSe~ -~~- ~€et~at~e~ ~e~ ~ ~e ~est~ ~e~tse~ ~~esse~ ~r ~ 6e~ae~ -Bes~e~s. The Architect's action will be taken with such reasonable prompmess as to cause no delay in the Work or in the activities of the Owner, Conh-actor or separate contractors, while allowing sufficient time in the Architect's professional judgment to permit adequate review. Review of such submittals is ~ conducted solelv for the benefit and arotection of the Owner and Contractor mav not rely u n ~ such review or approval as an acknowled~ement or certification that the submittal is accurate, comalete or proaoses work in compliance with all aspects of the Contract Documenu or applicable law._~t~~ese-e€~~+~g~ a~st~as~ -a~ ~~leEe~ess -e€ ~Ekef ~e~ai~s -stfsk ~as- ~s ~ -~aa~~ies, ~ -~ef -stt~sEa~ia~~g ~~st~e~ €ef -i~ts~a~aHee~~a~se~€-e~eeE-e~~ste~s; ~- e€ iv#iF# ~~ ~e -Fespefls~}~ ~€ -t~e ~ae,Fe~ -as- ~e~-~~e~e~asF-~Bese~e~- The Architect's review of the Contractor's submittals sha(t not retieve the Contractor of the obligations under Paragraphs 33, 3.5 and 3.12. The Architect's review and Owner's acceatance shall ~ot constitute approval of safety precautions or, s~esi€sa~} -state~ ~ -~e -Afsl~es~ -e€ any construction means, methods, techniques, sequences or procedures. Acce~tance or aaaroval of a~e-~s~tes~'s,a~e~a~F-e€-a specific item shall not indicate approval of an assembly of which the item is a component. 4.2.8 The Architect will prepare Change Orders and Construction Change Directives, and may authorize minor changes in the Work as provided in Paragraph 7.4. 4.2.9 The Architect will conduct inspections to determine the date or dates of Substantial Completion and the date of final completion, will receive and forward to the Owner for the Owner's review and records written warranties and related documenu required by the Contract and assembled by the Contractor, and will issue a final Certificate for Payment upon compliance with the ' requiremenu of the Contract Documenu. 4.2.10 If the Owner and Architect agree, the Architect will provide one or more project representatives to assist in carrying out the Architect's responsibilities at the site. The duties, responsibilities and limitations of authority of such project representatives shall be as set forth in an exhibit to be incorporated in the Contract Documenu. 4.2.11 The Architect shall reviewproverlv prepared timely requests ~ the Contractor for additional information about the Contractor pocuments or the Work. A proaerlv arepared request for information shall be submitted in a form arepared or aporoved ~ the Architect and shall include a detailed written statement indicatine the aarticular Contract Documenu in need of ciarification and the nature of tF information rectuested. _ The Architect's resaonse to su re uesu for information shall be made in writin~ or in the form of suaalemental drawin~s or snecifications as the Architect deems aaaropriate and shall be provided to the Contractor with reasonable vromamess. _ If no a~reement is made concemine the time within which a resnonse is reQUired, the Contractor shall make no claim on account of the Architect's failure to r.p ovide such a resnonse until twenri-one 21 davs after the written reQUest is made._ s~e~F- ~e~ -ar~ ~es~e ~,~ ~e~se~~g ~€et~se -e~eF ar~ ~eqa~er~er~s -e€ -~#e -6e~#ac,~ -9e~er~s -e~+ -w~i~e~- feq~esF -e€-e~ieF ~e -9~weF -ef -Ge~'asEef- - ~e ~4~sk~esE's- fes~eASe ~e ~ttsF~ -fe~es~s ~ -~e ~e -~~ -Feasefla~ ~e~es~s -a~ -w~i~ ~ ~3e -k~s -ag~ee~ -tt~ee- -~€-~e- ag~ee~e~ ~s -~e ~eHSe~g -~e -t~e ~ -w#is4} ~e~a~ie~s~-e€ -~ es~+a~e -+~i~r ~+s ~ag~ ~.? ~ie~-~e~ay-s~ ~-b~ feceg~~ ~ ~sse~~ ~€-€a~~e ~-~e-A~e~-~e ~ sas# ~~eEa~ie~s -~~ -~3 -~a~s -a€teF ~ ~es~ -fs- fHa`~°v~ ~~vr:r 4.2.12 Interpretations and decisions of the Architect will be consistent with the intent of and reasonably inferable from the Contract Documenu and will be in writing or in the form of drawings. ~~~a~e~s~-~esi~e~; , :r„1~" 4.2.13 ~e ~s~itest's ~esfsie~ts -e~t -~tai~ers -rela~g -te- aes~ketis ~e€~'e~ ~ -be -f~a~ -i€ -se~s~iste~ -~ ~e ~~ 4.3 CLAIMS AND DISPUTES 4.3.1 Definition. A Claim is a demand or assertion by one of the parties seeking, as a matter of right, adjustment or interpretation of Contract terms, payment of money, extension of time or other relief with respect to the terms of the Contract. The term "Claim" also includes other disputes and matters in question between the Owner and Contractor arising out of or relating to the Contract. Claims must be made by written notice. The responsibiliry to substantiate Claims shall rest with the party making the Claim. 4.3.2 Decision of Arcfiitect. Ela+~s, -+t~s~frg -~tese-~ a~eg~g -a~ ~ef -e~ -e~issiee -b}~ -t~e -~sE~esf; -s1~a~4~ -be- fe€e~e~ ' ~ c~ ~e ~e ~er~ -~ ac~iee -as -pfev~e~ -~- ~ab a~t~4---~-~esis~ie~-b}~-~e "_^-~~-as-~ew~ed-~i~r- ~~~~ ~i-4~ ~~ ~e -fe~a+~e~ -as -a -se~iefr Owner-Contractor Agreement Gene~al Conditions Supplement (For AIA ~oc. A201) Page - User pocument: A201 -- 12/29/1998. AIA License Number 100632, which expires on 12/7/1999 -- Page~